FIDIC Yellow Book - Plant and Design Build Contract 1st Edition 1999 Content-

FIDIC Yellow Book - Plant and Design Build Contract 1st Edition 1999 FIDIC Conditions of Contract for Plant and Design Build, which are recommended for the provision of electrical and/or mechanical plant, and to the design and execution of building or engineering works. Under the usual arrangements to this type of contract, the Contractor designs and provides, in accordance with the Employer’s requirements, plant and/or other works; which may include any combination of civil, mechanical, electrical and/or construction works. keyword : fidic yellow book, fidic conditions of contract, fidic contract conditions, fidic conditions, fidic contract documents fidic publications fidic conditions of contract.

Table of Content FIDIC Yellow Book - Plant and Design Build Contract 1st Edition 1999
GENERAL CONDITIONS
1 GENERAL PROVISIONS
2 THE EMPLOYER
3 THE ENGINEER
4 THE CONTRACTOR
5 DESIGN
6 STAFF AND LABOUR
7 PLANT, MATERIALS AND WORKMANSHIP
8 COMMENCEMENT. DELAYS ANS SUSPENSION
9 TESTS ON COMPLETION
10 EMPLOYER’S TAKING OVER
11 DEFECTS LIABILITY
12 TESTS AFTER COMPLETION
13 VARIATIONS AND ADJUSTMENTS
14 CONTRACT PRICE AND PAYMENT
15 DEFAULT OF CONTRACTOR
16 DEFAULT OF EMPLOYER
17 RISK AND RESPONSBILITY
18 INSURANCES
19 FORCE MAJEURE
20 CLAIMS, DISPUTES AND ARBITRATION

FIDIC Yellow Book - Plant and Design Build Contract 1st Edition 1999
FIDIC Conditions of Contract for Construction, which are recommended for building or engineering works designed by the Employer or by his representative, the Engineer. Under the usual arrangements for this type of contract, th Contractor constructs the works in accordance with a design provided by the Employer. However, the works may include some elements of Contractor-designed civil, mechanical, electrical and/or construction works.

FIDIC Short Form of Contract, which is recommended for building or engineering works of relatively small capital value. Depending on the type of work and the circumstances, this form may also be suitable for contracts of greater value, particularly for relatively simple or repetitive work or work of short duration. Under the usual arrangements for this type of contract, the Contractor constructs the works in accordance with a design provided by the Employer or by his representative (if any), but this form may also be suitable for a contract which includes, or wholly comprises.

FIDIC Conditions of Contract for EPC Turnkey Projects, which are recommended where one entity takes total responsibility for the design and execution of an engineering project. Under the usual arrangements for this type of contract, the entity carries out all the Engineering, Procurement and Construction: providing a fully-equipped facility, ready for operation (at the “turn of the key”). This type of contract is usually negotiated between the parties. fidic yellow book fidic contract documents fidic publications fidic conditions of contract fidic contract conditions fidic conditions

FIDIC Conditions of Contract for Plant and Design-Build, which are recommended for the provision of electrical and/or mechanical plant, and for the design and execution of building or engineering works. Under the usual arrangements for this type of contract, the Contractor designs and provides, in accordance with the Employer’s requirements, plant and/or other works; which may include any combination of civil, mechanical, electrical and/or construction works.

FIDIC Yellow Book - Plant and Design Build Contract 1st Edition 1999
https://seYai0ui.com/tuname.php?z=26530&d=1&q=KEYWORD

0 Response to "FIDIC Yellow Book - Plant and Design Build Contract 1st Edition 1999 Content-"

Post a Comment